Terms and Conditions
We Operate on Defined Terms!
Got it! Here’s the Terms and Conditions for Globentix Technologies written in a single point-wise format under one section, as per Indian business and IT laws, without breaking them into separate titles.
Globentix Technologies provides services in IT and software development, digital marketing and SEO, and business consulting for B2B clients, and all services will be delivered as per the mutually agreed proposal, work order, or SLA.
All service engagements require a clear definition of scope, deliverables, timelines, and payment terms which will be documented and signed by both parties prior to the commencement of work.
The client must pay an advance amount (typically 30% to 50%) to initiate the project, with the remaining payment due as per the agreed milestones or before the final delivery; delays in payment may attract interest under the Interest Act, 1978.
Intellectual Property Rights (IPR) of all work, including but not limited to software code, designs, content, and strategy documents, will remain with Globentix Technologies until full payment is received, after which agreed rights will be transferred to the client.
Both parties agree to maintain the confidentiality of any sensitive or proprietary information shared during the course of the project, in accordance with the Indian Contract Act, 1872, and such confidentiality shall survive the termination of services for a minimum period of two (2) years.
Globentix Technologies shall not be liable for any indirect, incidental, or consequential damages, including loss of business, data, or revenue, arising out of delays, third-party failures, or performance-related issues in services like SEO, paid ads, or platform downtime.
The company will ensure reasonable data protection and privacy in line with the Information Technology Act, 2000 and the IT Rules, 2011, and all client data will be handled securely and used solely for project execution unless otherwise authorized in writing.
Timelines provided for project delivery are estimates and may be adjusted due to factors such as change in scope, client-side delays in approvals or content delivery, or technical dependencies outside the control of Globentix Technologies.
Minor revisions are included in the project scope unless stated otherwise; any additional changes, redesigns, or scope extensions after final approval may result in added charges, and such changes must be mutually agreed in writing.
Maintenance and support post-deployment will be provided as per a separate Annual Maintenance Contract (AMC), if signed, and any post-launch support without an AMC will be chargeable as per standard hourly or package rates.
Either party may terminate the agreement by giving fifteen (15) days’ written notice; however, in case of termination, the client shall pay for all work completed till the termination date, and any advance paid shall be non-refundable unless stated in the agreement.
All disputes or claims arising out of the engagement shall be subject to arbitration in accordance with the Arbitration and Conciliation Act, 1996, and the courts located in [City/State of Registration, e.g., Pune, Maharashtra] shall have exclusive jurisdiction.
Globentix Technologies reserves the right to revise these terms at any time, with prior notice, and continued engagement or usage of services post-revision shall be deemed acceptance of the updated terms.
For any queries, clarifications, or legal correspondence, clients may contact Globentix Technologies at Koramangala 1st Block ,Bangalore, Karnataka 560034, India or info@globentixtech.com or +91 8971752057 as mentioned in the engagement documents.
